LAKESIDE CARPENTRY
& RENOVATIONS

Welcome to Lakeside Carpentry & Renovations. By using our website and services, you agree to comply with and be bound by the following terms and conditions. Please read them carefully before engaging with our services or website.

​

1. Acceptance of Terms

By accessing or using our website, services, or entering into an agreement for renovation or carpentry work, you agree to these Terms and Conditions, our Privacy Policy, and any other legal notices or guidelines posted on our website. If you do not agree with these terms, please refrain from using our website and services.

​

2. Services

Lakeside Carpentry & Renovations provides professional carpentry and renovation services, including but not limited to home improvement, repairs, remodeling, and custom renovations. All services are subject to availability and may vary based on location, project type, and other factors.

 

3. Estimates and Contracts

• Estimates: We provide free estimates under certain circumstances, i.e, offers, newsletter, etc. These estimates are based on the information provided and are subject to change if the scope of the project evolves or if additional issues are discovered during the work.

• Contracts: Once an estimate is accepted, we will issue a formal contract outlining the scope of work, costs, payment terms, and timelines. Work will commence once the contract is signed and any agreed-upon deposits are received.

 

4. Payments

• Deposits: A deposit may be required to schedule and secure your project. This will be outlined in your contract.

• Payment Terms: Full payment terms will be provided in the contract. Payments must be made according to the agreed-upon schedule.

• Late Payments: Failure to make timely payments may result in delays, additional fees, or suspension of work until payment is received.

 

5. Changes to Scope of Work

If any changes to the scope of work are required after the contract has been signed, a written agreement (change order) must be approved by both parties. This may result in additional costs or extensions to the project timeline.

 

6. Cancellation and Refund Policy

• Cancellation by Client: Clients may cancel their project before work begins, but cancellation fees may apply if materials have been purchased or if significant time has been invested in planning. The terms will be outlined in your contract.

• Cancellation by Company: We reserve the right to cancel or reschedule work due to unforeseen circumstances, such as weather, safety concerns, or inability to access the site. We will notify the client as soon as possible if this occurs.

 

7. Warranties

• Workmanship Warranty: We stand behind the quality of our work. All labor and workmanship are warranted for [Insert Warranty Period] from the completion of the project, provided the work was not altered or damaged after completion.

• Material Warranties: Any manufacturer warranties on materials used will be passed along to the client.

 

8. Liability

• Property Damage: We take great care in our work and will make every effort to avoid damage to your property. However, we are not liable for pre-existing conditions or any damage resulting from conditions outside of our control, such as weather or structural instability.

• Third-Party Contractors: In some cases, we may recommend or work with third-party contractors for specific tasks. We are not responsible for the actions, performance, or liability of third-party contractors unless otherwise stated.

 

9. Website Use

• Content: The content on our website, including images, text, and graphics, is for informational purposes only. You may not copy, distribute, or modify any content without our express written consent.

• Third-Party Links: Our website may contain links to third-party websites. We are not responsible for the content, privacy policies, or practices of any third-party websites.

 

10. Limitation of Liability

To the fullest extent permitted by law, Lakeside Carpentry & Renovations shall not be held liable for any indirect, incidental, special, consequential, or punitive damages, including but not limited to lost profits, loss of business, or other damages arising from the use of our services or website.

 

11. Indemnification

You agree to indemnify, defend, and hold harmless Lakeside Carpentry & Renovations and its employees, contractors, and affiliates from any claims, damages, liabilities, and expenses (including legal fees) arising from your use of our services, violation of these Terms, or any unlawful activity related to your account.

 

12. Governing Law

These Terms and Conditions shall be governed by and construed in accordance with the laws of [Your State/Province], without regard to its conflict of law provisions. Any disputes arising under or related to these Terms shall be resolved in the courts located in [Your State/Province].

 

13. Changes to These Terms

We may update these Terms and Conditions from time to time. Any changes will be posted on this page, and the "last updated" date will be modified accordingly. By continuing to use our services or website after any changes, you accept the modified Terms.

 

14. Contact Us

If you have any questions regarding these Terms and Conditions, please contact us at:

​

Lakeside Carpentry & Renovations

contact@lakesidecarpentry.ca

#1-289-783-2651

www.lakesidecarpentry.ca